Skip to content
Law Society of Scotland
Search
Find a Solicitor
Contact us
About us
Sign in
Search
Find a Solicitor
Contact us
About us
Sign in
  • For members

    • For members

    • CPD & Training

    • Membership and fees

    • Rules and guidance

    • Regulation and compliance

    • Journal

    • Business support

    • Career growth

    • Member benefits

    • Professional support

    • Lawscot Wellbeing

    • Lawscot Sustainability

  • News and events

    • News and events

    • Law Society news

    • Blogs & opinions

    • CPD & Training

    • Events

  • Qualifying and education

    • Qualifying and education

    • Qualifying as a Scottish solicitor

    • Career support and advice

    • Our work with schools

    • Lawscot Foundation

    • Funding your education

    • Social mobility

  • Research and policy

    • Research and policy

    • Research

    • Influencing the law and policy

    • Equality and diversity

    • Our international work

    • Legal Services Review

    • Meet the Policy team

  • For the public

    • For the public

    • What solicitors can do for you

    • Making a complaint

    • Client protection

    • Find a Solicitor

    • Frequently asked questions

    • Your Scottish solicitor

  • About us

    • About us

    • Contact us

    • Who we are

    • Our strategy, reports and plans

    • Help and advice

    • Our standards

    • Work with us

    • Our logo and branding

    • Equality and diversity

  1. Home
  2. For members
  3. Journal Archive
  4. Issues
  5. August 2021
  6. Liquidated damages and the effect of termination

Liquidated damages and the effect of termination

A Supreme Court ruling has brought welcome clarity for the construction sector on the drafting and application of liquidated damages clauses, particularly where a contract is terminated
11th August 2021 | Kirstin Beattie

A Supreme Court decision on the interpretation of liquidated damages clauses has provided reassurance to the construction sector on the relationship between these clauses and termination.

Although the case of Triple Point Technology Inc v PTT Public Company Ltd [2021] UKSC 29 originated from the TCC and is supremely relevant to the construction industry, the Supreme Court judgment is in fact a decision on the interpretation of an IT contract rather than a construction one.

The contractor (Triple Point) was obliged to provide certain services relating to the design, installation, maintenance and licensing of software, and was to be paid on completion of certain milestones.

Stages one and two were completed (although late), and the following stages were never completed. The contract was ultimately terminated by the employer (PTT).

It’s a fairly common scenario to those of us working in the construction sector, so why has this decision from the Supreme Court been so eagerly anticipated?

Key issues

While there were three issues on appeal, the key issue for the construction sector was the question of whether or not liquidated damages were payable at all where a contractor was in delay at the point of termination and work remained outstanding at that point.

There were also questions raised on the interpretation of exceptions to caps on liability, including whether “negligence” means the tort of negligence or whether it includes breach of the contractual duty of skill and care, and whether any liquidated damages could count towards the overall contractual cap on liability.

The latter two issues were decided on the specific drafting of the cap on liability. However, the liquidated damages clause provided for liquidated damages to be paid for each day of delay by the contractor “from the due date for delivery up to the date [the employer] accepts such work”.

This is similar to most standard form drafting in construction contracts, including the JCT and SBCC provisions, and so the court’s decision on this issue will clearly have wider implications for the construction sector.

The appeal decision

So what happens to accrued liquidated damages (“LDs”) when the contractor fails to complete the works before the contract is terminated?

There were three possible conclusions the court could reach, all of which had been supported by previous authority:

  1. the LDs clause does not apply at all;
  2. the LDs clause applies only until the point of termination; or
  3. the LDs clause applies until a second contractor achieves completion.

The Supreme Court overturned the decision in the Court of Appeal and found that LDs will generally accrue until the point of termination, notwithstanding the fact that the works were never completed by the contractor and thereafter general damages would be recoverable.

It found that unless there is clear and specific wording to the contrary, the rights to LDs which have accrued as at termination will survive.

The Supreme Court also held this interpretation more in keeping with commercial reality, and the accepted function of liquidated damages, which was to provide a remedy that is predictable and certain for a particular event, such as a delay to completion – an interpretation which is likely to accord with the views of many in the construction industry.

Practical consequences

There are a number of key takeaways from this decision for those involved in negotiating LDs provisions, or caps on liability.

  • If you do not want accrued rights to survive termination then you need to say so in your contract.
  • General damages for breach of contract will apply post-termination. If an employer wants the LDs provision to survive until completion of the works by a second contractor, they will have to say so explicitly (although there must be questions as to whether a contractor would agree to that approach).
  • Caps on liability need to be carefully drafted, as do any applicable exclusions from a cap. There are usually certain exclusions to caps (although normally only for death and personal injury). In this case, there was an exclusion for negligence (as opposed to the more common wording of “gross negligence”), which was wide enough to cover contractual breaches of the obligation to exercise skill and care. This meant these breaches were excluded from the cap on liability.
  • If you have specific remedies for certain breaches of contract, such as LDs for a delay to completion, consider from the outset whether the value of these is to be included in any applicable cap or whether they should be standalone remedies which do not count towards the cap. If they are included within a general cap, take that into consideration when agreeing the level of cap.

The construction industry is likely to welcome the Supreme Court’s decision on the application of LDs clauses pre- and post-termination.

While much will turn of the drafting of the clause itself, with the similarities between the clause in dispute and those clauses found in many of the standard form contracts, the decision simply reinstates what was previously understood to be the recognised position – LDs will apply up to termination and then general damages thereafter.

The decision also brings welcome clarity on the drafting of exclusions from caps on liability and serves as a reminder to those seeking, or asking for such clauses, that care should be taken to ensure there are no ambiguities which might ultimately make the cap redundant.

The Author

Kirstin Beattie is an associate in Construction & Projects at Burness Paull

Share this article
Add To Favorites
https://lawware.co.uk/

Regulars

  • People on the move: August 2021
  • Book reviews: August 2021
  • Reading for pleasure: August 2021

Perspectives

  • President's column: August 2021
  • Editorial: Defence questions
  • Profile: Keith Hamilton

Features

  • The cost of bad advice
  • Licensing the great outdoors
  • In care, in family?
  • Executor removal: a high bar
  • Time to push for family ADR
  • Some are less equal
  • Body donation: practice points

Briefings

  • Criminal court: Sentencing deconstructed
  • Family: Litigation and lottery wins
  • Human rights: Reinforcing the right to be forgotten
  • Pensions: Plugging the LGPS exit credit hole
  • Criminal law: The future of sexual offence trials
  • Scottish Solicitors' Discipline Tribunal
  • Property: Heat networks: the key to low-carbon heating?
  • In-house: Power of the nudge

In practice

  • SLAB not liable for interest – but should be: SAC
  • The Scottish Legal Walks are back!
  • Risk management post-COVID-19
  • Civil court hearings: seeking common ground
  • The Word of Gold: Scratch my back?
  • The Eternal Optimist: Living up to the name
  • Ask Ash: Groundhog day again?

Online exclusive

  • Competition and consumer law: time for a shakeup
  • SSSC hearings: why the move to opt-in
  • Liquidated damages and the effect of termination
  • State aid in the post-Brexit age

In this issue

  • Opinion: Andrew Stevenson
  • The pros & cons of outsourced cashroom services
  • The Cloud: let’s keep IT simple
  • Sign up for Remember A Charity will campaign week

Recent Issues

Dec 2023
Nov 2023
Oct 2023
Sept 2023
Search the archive

Additional

Law Society of Scotland
Atria One, 144 Morrison Street
Edinburgh
EH3 8EX
If you’re looking for a solicitor, visit FindaSolicitor.scot
T: +44(0) 131 226 7411
E: lawscot@lawscot.org.uk
About us
  • Contact us
  • Who we are
  • Strategy reports plans
  • Help and advice
  • Our standards
  • Work with us
Useful links
  • Find a Solicitor
  • Sign in
  • CPD & Training
  • Rules and guidance
  • Website terms and conditions
Law Society of Scotland | © 2025
Made by Gecko Agency Limited